Terms and conditions 2019
Our terms and conditions once a commission has been placed this is non-refundable due to the time and professional services that have been given for you the client.
If you have placed your commission and do not wish to proceed you may keep the deign pack and all of the written specifications.
Once you have entered the next 2nd stage payment making the 50 % payment for production this is not fully refundable., you will be asked to sign the final plan for production, an electronic copy is acceptable, as we will be ordering materials for the furniture to be built we will only refund 50 % of the payments at that stage subject to directors’ approval, once plans have been signed this is a non-refundable
Balance payment is required 7 days prior to shipment of goods.
Balance of installation payment (we let our clients hold 30 % of the installation cost for 3 whole months) payable after 3 months.
This document sets out the terms and conditions under which you are making your purchase and makes the commitment we are making to you as a customer of Designers of Knightsbridge ltd, 239 High street Kensington, London W8 6SN. Company number registration number :06515357
We also take this time to thank you for your custom,
The furniture is guaranteed for 10 years, this guarantee is in addition to and does not limit or exclude any legal rights you may have in relation to goods which do not conform with the contract under the consumer rights act 2015 or otherwise.
Cancellation or variation: Cancellation or variation of orders will only be accepted where a Director of the Company has agreed it in writing and on condition that you reimburse the Company for all costs and expenses plus any losses and damages resulting from the cancellation or variation. A reasonable charge will be made for the administration costs incurred by the Company in relation to any agreed variations.
Limits of contract: No order submitted by you is accepted by the Company unless and until confirmed in writing by the Company’s authorised representative. Our quotation includes only the work and materials specified therein. Any subsequent change of specification may entail a revision of the price and/or completion date. Any descriptions or illustrations contained in the Company’s catalogues, portfolios or brochures are issued or published for the sole purpose of giving an approximate idea of the Goods described in them are indicative only, they will not form part of this Contract. Drawings that accompany the quotation are indicative only, as the site or other circumstances may require amendments. Drawings should not be scaled.
Specification: Designers of Knightsbridge reserves the right to amend the specification of furniture, including without limitation where such amendments are required to conform with any applicable statutory or EU requirements. Any changes Designers of Knightsbridge makes to the specification of goods will not materially affect their quality or performance.
Delivery: Designers of Knightsbridge will confirm the week of delivery prior to delivery. Whilst Designers of Knightsbridge does everything possible to meet the agreed delivery date, circumstances occasionally require it to change. If this happens, Designers of Knightsbridge will contact you with reasonable notice to agree a new delivery date, which will be confirmed in writing. Time of delivery shall not be of the essence of the Contract. Should delivery not be made on the delivery date due to you or your representative requiring a later delivery date, storage will be charged at £200 plus VAT per week thereafter. If you cancel delivery with less than one day’s notice or we are unable to deliver for the reasons set out above a re-delivery charge will be payable by you. On delivery, an inventory of goods delivered will be provided for you or your representative to sign. This document will act as proof of delivery and the condition of the goods. Any subsequent loss or damage is your responsibility.
The Company shall not be liable to you for any loss of profit, loss of business or depletion of goodwill or for any indirect or consequential loss or damage, costs, expenses or other claims for consequential compensation whatsoever (howsoever caused) which arise out of or in connection with the Contract.
Goods supplied under this Contract will become your property upon the receipt by Designers of Knightsbridge of full payment in cleared funds of all sums due under the Contract. Risk in the goods will pass to you upon delivery of the goods to you. Subject to the other provisions of these conditions the Company will not be liable to you for any direct, indirect or consequential loss, costs, damages, charges or expenses caused directly or indirectly by any delay in the delivery of the goods or completion of installation. If the goods are not delivered at the agreed time or within the agreed period, you shall not be entitled to terminate or rescind the Contract unless (i) you have a right to do so under the Consumer Rights Act 2015 or (ii) such delay on the part of the Company exceeds 90 days. If for any reason you will not accept delivery of any of the goods when they are ready for delivery, or the Company is unable to deliver the goods because you have not provided appropriate instructions, access, documents, licences or authorisations, the Company may store the goods until delivery whereupon you will be liable for all related costs and expenses (including, without limitation, storage and insurance).
Designers of Knightsbridge is not responsible for the provision of waste pipes, water, electricity or gas services and for any consequential effects of the siting of these on the kitchen design and installation and also any costs or consequential effects of any re-siting of these supplies necessary as a result of the kitchen installation. All kitchen services need to be identified and discussed during our survey. Any services altered or added at a later date are not our responsibility and may have cost and time implications to our work.
Installation: Our fitting charge is only to fit the furniture. It does not include any building or preparation work, removal of existing kitchen or furniture, tiling, flooring or lighting, unless specified. It is your responsibility to ensure that the site is ready for installation.
Protection of floor and wall finishes is your responsibility, although will make every effort to avoid any damage.
General: The Company reserves the right to defer the date of delivery or to cancel the Contract (without liability to you) if it is prevented from or delayed in the carrying on of its business due to circumstances beyond the reasonable control of the Company including, without limitation, acts of God, governmental actions, war or national emergency, acts of terrorism, protests, riot, civil commotion, fire, explosion, flood, epidemic, lock-outs, strikes or other labour disputes (whether or not relating to either party’s workforce), or restraints or delays affecting carriers or inability or delay in obtaining supplies of adequate or suitable materials provided that, if the event in question continues for a continuous period in excess of 90 days, you shall be entitled to give notice in writing to the Company to terminate the Contract. Designers of knightsbridge will take reasonable steps to minimise or prevent any delays. If any provision of the Contract is found by any court, tribunal or administrative body of competent jurisdiction to be wholly or partly illegal, invalid, void, voidable, unenforceable or unreasonable it shall to the extent of such illegality, invalidity, voidness, voidability, unenforceability or unreasonableness be deemed severable and the remaining provisions of the Contract and the remainder of such provision shall continue in full force and effect.
Failure or delay by the Company in enforcing or partially enforcing any provision of the Contract will not be construed as a waiver of any of its rights under the Contract and any waiver by the Company of any breach of, or any default under, any provision of the Contract by you will not be deemed a waiver of any subsequent breach or default and will in no way affect the other terms of the Contract. The parties to this Contract do not intend that any term of this Contract will be enforceable by virtue of the Contracts (Rights of Third Parties) Act 1999 by any person that is not a party to it. The formation, existence, construction, performance, validity and all aspects of the Contract shall be governed by English law and the parties submit to the exclusive jurisdiction of the English courts, provided that if you live in Scotland or Northern Ireland you can instead bring legal proceedings in the Scottish or the Northern Irish courts, respectively.
Designers of Knightsbridge LTD
239 High Street Kensington, London W8 6SN
Tel: 020 3755 3125
VAT no: GB937318506 Company reg: 06515357
Terms & Conditions 2019